1 / 24

No Excuse Incentive Provisions Survey

No Excuse Incentive Provisions Survey . ~ May 2010 ~. AASHTO S UBCOMMITTEE ON C ONSTRUCTION Contract Administration Section. No Excuse Incentive Provisions Survey Table of Contents No Excuse Incentive Provision (Definition) 3 Survey Questions:

sulwyn
Download Presentation

No Excuse Incentive Provisions Survey

An Image/Link below is provided (as is) to download presentation Download Policy: Content on the Website is provided to you AS IS for your information and personal use and may not be sold / licensed / shared on other websites without getting consent from its author. Content is provided to you AS IS for your information and personal use only. Download presentation by click this link. While downloading, if for some reason you are not able to download a presentation, the publisher may have deleted the file from their server. During download, if you can't get a presentation, the file might be deleted by the publisher.

E N D

Presentation Transcript


  1. No Excuse Incentive Provisions Survey ~ May 2010 ~ AASHTO SUBCOMMITTEE ON CONSTRUCTION Contract Administration Section

  2. No Excuse Incentive Provisions Survey Table of Contents No Excuse Incentive Provision (Definition) 3 Survey Questions: 1. Does your State use NEI provisions? 4 2. How many projects per year use NEI provisions? 5 3. What are State’s criteria for use? 6 4. What is the most common reason for setting the NEI date? 7 5. What catastrophic events are described as exceptions to the “No Excuse” coverage? 8 6. What criteria are used in developing the NEI contract amount? 9 7. Does the NEI provision describe the anticipated time for State review of Contractor submissions? 10 8. What percentage of contracts pay the NEI amount? 11 9. Are there any special precedence for paying the NEI amount? 12 NEI Provisions and Web Links 13

  3. Definition: No Excuse Incentive Provision No Excuse Incentive (NEI) Provision is a contract provision that provides a monetary incentive for early completion. A “drop-dead date” is usually specified for the completion of a phase of work or for the entire project. If the work is completed on or in advance of this date, the contractor will receive the full incentive payment. There are no excuses for adjusting this date including utilities, permitting, change orders, weather, differing site conditions, or any other cause short of a natural catastrophe.

  4. 32 States Responded Yes: AL, FL, GA, IA, MA, MN, MO, NC, PA, SC, SD, VA, WI, WY No: AK, AR, DE, IN, KS, NE, NH, NM, OK, OR We did evaluate but no longer use: CO, CT, ID, KY, ND, NY, OH, WV

  5. More than Two: AL, SC, WI One to Two: GA, IA, MA, MN, MO, NC, PA, SD, VA Less than One: FL, WY

  6. 3. What are State’s criteria for use? AL: Typically use this provision in an effort to minimize disruptions to traffic (high traffic volumes, narrow lanes, detours, etc). FHWA Tech Advisory T 5080.10 "Incentive/Disincentive for Early Completion" used as a guide. FL: FDOT guidance document: http://www.dot.state.fl.us/construction/Manuals/cpam/New%20Clean%20Chapters/Chapter1s2.pdf GA: Traffic volume, location and type of work IA: Rarely used. Completion of a major new bypass facility due to local impacts has been a candidate project. No written policy exists. MA: We generally apply the project selection criteria contained in the 02-08-1989 FHWA Technical Advisory T 5080.10 "Incentive/Disincentive (I/D) For Early Completion" to NEI project selection. MN: These (contract amount, type of work, traffic volume, location, school opening dates) are all considerations. MO: Traffic volume, location and opening date NC: High user cost and/or facility need PA: So far, completing a multi-year project one season early. SC: It varies. It may be considered on any high profile project. High traffic volumes are one of the main considerations. SD: Extreme circumstances were traffic is critical. Typically used in and around Sturgis for completion of work or phase prior to the annual Sturgis Motorcycle Rally. VA: There is not a state policy governing NEI provisions. We look at traffic volume, impact to the public, business/economic impact, etc. WI:http://roadwaystandards.dot.wi.gov/standards/fdm/19-15-018.pdf WY: Usually used to reduce impacts to a local community and are for a portion of the work that effects the travel way. Usually not for the completion of the project as a whole.

  7. 4. What is the most common reason for setting the NEI date? AL: Dates are set to minimize disruptions impacts to traffic flow. FL: Accelerated completion of the project or a specific milestone component of the project GA: Road user costs IA: Opening to traffic MA: The elimination of a time-consuming detour and/or the elimination of a detour that has been in effect for an inordinate amount of time. MN: End of the construction season MO: Opening date to meet public commitment NC: High user cost and/or facility need PA: Meeting a completion date that is earlier than the original contract completion date. SC: Special events, school openings, seasonal traffic fluctuations. SD: Special event date VA: Impact to the public and business/economic impact. WI: Work affecting another adjacent project/Special event date WY: Usually for a road to be closed, get work done and reopen.

  8. Other Comments: FL: In the event of a catastrophic event (i.e., hurricane or a declared state of emergency) directly and substantially affecting the Contractor’s operations on the Contract, the Contractor and the Department shall agree as to the number of calendar days to extend the “Bonus Completion Date”. MA: "...catastrophic event and/or a declared state of emergency..." SC: Catastrophic events (hurricane or a declared state of emergency.) VA: Act of war etc. These must meet the "catastrophic event" criteria to be considered. WI: Industry wide labor disputes / Acts of the government

  9. Other Comments: WI: Business/economic impact

  10. Yes: MA No: AL, FL, GA, IA, MN, MO, NC, PA, SC, SD, VA, WI, WY

  11. 9. If a contractor was delayed by action outside of its control, resulting in the loss of the NEI, is there any special precedence for the state being required to pay the NEI amount? FL: Current Language: However, notwithstanding anything above to the contrary, upon the Contractor’s written request being made directly to the Chief Engineer, with copies provided to both the Resident Construction Engineer and the District Construction Engineer, the Department reserves unto the Chief Engineer, in his sole and absolute discretion, according to the parameters set forth below, the authority to make a determination to either fully enforce the above provisions with no modification, modify the “Bonus Completion Date” by moving it, or both modify the “Bonus Completion Date” by moving it and also modify the “Bonus” amount by reducing it. IA: We are currently evaluating a situation where another bridge project located within the project limits was delayed beyond the contractor’s control. This is a site of work issue that was not conveyed in the proposal.

  12. NEI Provisions and Web Links State Guidance Documents Caltrans: Caltrans Alternative Procurement Guide link: http://www.dot.ca.gov/hq/oppd/contracting/AlternativeProcurementGuide.pdf See Part 4.5 - No Excuse Incentives FL: http://www.dot.state.fl.us/construction/Manuals/cpam/New%20Clean%20Chapters/Chapter1s2.pdf WI:http://roadwaystandards.dot.wi.gov/standards/fdm/19-15-018.pdf State NEI Provisions AL: Example NEI provision attached. FL: ftp://ftp.dot.state.fl.us/LTS/CO/Specifications/WorkBook/Jul2010/SP0081300BCD.pdf SC: Example NEI provision attached. WI: Example NEI provision and related info attached.

  13. Wisconsin Example NEI Provision and Related Info: Incentive/Disincentive for Interim Completion of Work, Item 108.3100.S. A General This item shall consist of either an incentive payment or a disincentive pay reduction as specified below. The contractor shall complete all of the work necessary to enter requirements for work completion on this contract prior to 12:01 AM date, or within such extended time as may be allowed. The completion time allowed for this contract is based on an expedited work schedule. Under this Incentive/Disincentive plan, no time extensions will be granted for adverse weather conditions; for delays in material deliveries; or for labor disputes unless it can be shown that such disputes are industry wide. Each day shall be defined as a 24 hour period beginning at 12:01 AM. The maximum incentive payment, as shown on the Schedule of Items, is for department accounting purposes. The actual incentive payment the contractor may receive shall be in accordance to Section B of this provision. Incentive payments will not be considered as part of the money value of the work completed for computing time extensions. B Incentive Payment The contractor shall be entitled to an incentive payment for completion of all of the work necessary to enter requirements for work completion on this contract prior to 12:01 AM, date or such extended time as may be allowed. The incentive payment shall be paid at the rate of $Enter incentive amount per calendar day for each day or portion thereof, of completion prior to 12:01 AM date. The maximum amount of incentive payment shall not exceed $Enter maximum incentive amount. C Disincentive Pay Reduction Should the contractor fail to complete all of the work necessary to enter requirements for work completion under this contract prior to 12:01 AM, date or within such extended time as may be allowed, the contractor shall be liable to the department for a pay reduction in the amount of $Enter the disincentive amount per day or portion thereof, for each calendar day after 12:01 AM, date that work remains incomplete. If contract time expires before completing all work specified in the contract, additional liquidated damages in accordance to 108.11 of the standard specifications will be affixed in addition to the disincentive pay reduction. D Measurement and Payment Incentive/Disincentive for interim Completion of Work will be measured by the calendar day and will be paid for at the contract unit price per calendar day. The unit price per day based on the incentive pay adjustment shall be compensation in full for completing the work as hereinbefore specified. The unit price per day based on the disincentive pay reduction shall be assessed for failing to complete all the work as hereinbefore specified.

  14. Wisconsin Example NEI Provision and Related Info (continued) : • 108-056 (20080501) • Prior to beginning operations under this contract, submit in writing the proposed schedule of operations to the engineer for approval. • At the beginning of (List appropriate construction operations) operations, close (Route # / Street Name) to through traffic for a maximum of (Enter #) of calendar days calendar days. Do not reopen until completing the following work: (Describe Work) • Supplement subsection 108.11 of the standard specifications as follows: • If the contractor fails to complete the work necessary to reopen (Route # / Street Name) to traffic within (# of calendar days) calendar days, the department will assess the contractor $dollar amount for damages in interim liquidated damages for each calendar day the contract work remains incomplete beyond (# of calendar days) calendar days. An entire calendar day will be charged for any period of time within a calendar day that the road remains closed beyond 12:01 AM. • This language is usually included in the STSP above: • The department will not grant time extensions to the interim completion dates specified above for the following: • 1.Severe weather as specified in subsection 108.10.2.2 of the standard specifications. • 2.Labor disputes that are not industry wide. • 3.Delays in material deliveries. • If contract time expires prior to completing all work specified in the contract, additional liquidated damages will be affixed in accordance to subsection 108.11 of the standard specifications.

  15. ALABAMA DEPARTMENT OF TRANSPORTATION DATE: April 18, 2007 Special Provision No. 06-0523-R2 SUBJECT: Incentive Payments, Disincentive Deductions, Performance Bonus and Liquidated Damages, Projects No. IM-NHF-I065(375) and NHF-I065(378), Montgomery County. Alabama Standard Specifications, 2006 Edition, SECTIONS 101 and 108 shall be amended as follows: SECTION 101 DEFINITION OF TERMS 101.01 Definitions. (b) TERMS. This Subarticle (101.01(b)) shall be amended by adding the following definition thereto: Incentive Payments and Disincentive Deductions. A contract provision in which is given the means by which: - the Contractor is compensated a certain amount of money for each hour or day a phase of the project or a defined period of construction work is completed ahead of schedule and; - the Contractor is assessed a deduction for each hour or day the Contractor overruns the time set for the completion of a phase of the project or a defined period of construction work. The Incentive/Disincentive provision is intended to motivate the Contractor so that work will be completed on or ahead of schedule on critical projects where traffic inconveniences and delays must be minimized. Performance Bonus. A contract provision in which is given the means by which a Contractor is compensated a certain amount of money for each hour or day a phase of the project or a defined period of construction work is completed ahead of schedule. The Performance Bonus is intended to motivate the Contractor so that work will be completed on or ahead of schedule on critical projects where traffic inconveniences and delays must be minimized.

  16. 2 Special Provision No. 06-0523-R2 SECTION 108 PROSECUTION AND PROGRESS 108.08 Determination of Contract Time. (a) GENERAL. This Subarticle (108.08(a)) shall be replaced by the following: (a) ASSIGNMENT OF TIME. The calendar date of October 15, 2009 is assigned for completion of all of the work included in the contract. Calendar days are assigned to defined periods of time within the overall time allowed for the completion of all work. These periods of time are defined for the completion of significant portions of the work. Incentive payments, disincentive deductions and performance bonus payments will be made depending on the progress of construction during these defined periods of time. The first defined period of time is the time allowed from the beginning of contract time charges until the north bound traffic is placed on the newly constructed pavement in the median during Phase IV A shown in the Sequence of Construction on the Plans. The second defined period of time is the time allowed from the completion of all of the work in the first defined period of time until the north bound traffic is placed on the reconstructed north bound lanes. During the second defined period of time the Contractor shall keep one lane in each of the following ramps (including access to the ramps) open except for the time allowed for closure of the ramps for ramp construction: - the north bound entrance ramp from US 80 onto I-65; - the north bound exit ramp from I-65 onto the Southern Bypass; - the north bound entrance ramp from the Southern Bypass onto I-65. Each ramp may be closed for a maximum time period of 4 calendar days for the construction of the ramp. The third defined period of time is the time after the completion of all of the work in the second defined period of time for the continuation of the work before south bound traffic is shifted to the pavement in the median. The fourth defined period of time is the time allowed from the placement of south bound traffic in the median during Phase IV B in the Sequence of Construction until the south bound traffic is placed on the reconstructed southbound lanes.

  17. 3 Special Provision No. 06-0523-R2 • 108.09 Extension of Contract Time. • This Article (108.09) shall be replaced by the following: • 108.09 Extension of Contract Time. • Requests for extensions of time will not be considered. Weather will not be considered as a reason for a time extension. Regardless of any delays encountered the Contractor is expected to increase the equipment, labor force, and working hours in order to complete the project within the assigned contract time. • The defined periods of time for construction within the overall contract time were set based on the assumption that unsuitable material will be encountered under the existing roadway pavement. • 108.10 Failure to Complete Work Within Contract Time. • This Article (108.10) shall be replaced by the following: • 108.10 Failure to Complete Work Within The Contract Time Periods. • (a) TIME. • Time is of the essence in completing the contract work. It is in the interest of the public and the State to have the work completed as quickly as possible. Any delay in completing this work will inconvenience and be expensive to the traveling public, obstruct traffic, interfere with and delay business and commerce and increase the cost of the project to the State. Furthermore, during each day that the work is under construction, the users of the highway will incur costs as a result of delays caused by construction. • (b) PERFORMANCE BONUS FOR THE FIRST DEFINED PERIOD OF TIME. • The first defined period of time is the time allowed from the beginning of contract time charges until the north bound traffic is placed on the newly constructed pavement in the median during Phase IV A shown in the Sequence of Construction on the Plans. The Contractor will be paid a performance bonus of $1,000,000 if north bound traffic is placed on the newly constructed pavement in the median by April 1, 2008. • (c) INCENTIVE/DISINCENTIVE FOR THE SECOND DEFINED PERIOD OF TIME. • 1. WORK ASSIGNED FOR THE SECOND DEFINED PERIOD OF TIME. • The second defined period of time is the time allowed from the completion of all of the work in the first defined period of time until the north bound traffic is placed on the reconstructed northbound lanes.

  18. 4 Special Provision No. 06-0523-R2 • 2. INCENTIVE PAYMENTS FOR SECOND DEFINED PERIOD OF TIME. • a. Overall Incentive for Second Defined Period of Time • An incentive payment will be made to the Contractor if the work assigned for the second defined period of time is completed within 17 calendar days. For each full calendar day that the work in the second defined period of time is completed before the expiration of 17 calendar days assigned for this work, the Contractor will be paid $100,000. • b. Incentive for Ramp Closure and Construction within Second Defined Period of Time. • During the second defined period of time the Contractor will be allowed 4 calendar days to close and complete the construction of the following ramps: • - the north bound entrance ramp from US 80 onto I-65; • - the north bound exit ramp from I-65 onto the Southern Bypass; • - the north bound entrance ramp from the Southern Bypass onto I-65. • The 4 calendar day time periods for the work on each ramp do not have to be the same 4 calendar day time periods. • For each full calendar day that the work is completed on the northbound entrance ramp from US 80 onto I-65 before the expiration of the 4 calendar days assigned for this work, the Contractor will be paid $10,000. • For each full calendar day that the work is completed on the northbound exit ramp from I-65 onto the Southern Bypass before the expiration of the 4 calendar days assigned for this work, the Contractor will be paid $10,000. • For each full calendar day that the work is completed on the northbound entrance ramp from the Southern Bypass onto I-65 before the expiration of the 4 calendar days assigned for this work, the Contractor will be paid $10,000. • The incentive will be paid if it is earned during days of work when disincentive deductions are being made from the payment due the Contractor during the overall second defined period of time. Incentive payments (and disincentive deductions) will be calculated separately for each ramp. • c. Overall Incentive plus Incentive for Ramp Closure and Construction. • The Contractor will be paid the overall incentive payment and the incentive payments for ramp closures and construction if the required work is completed within the times allowed to warrant incentive payments.

  19. 5 Special Provision No. 06-0523-R2 • 3. DISINCENTIVE DEDUCTIONS FOR SECOND DEFINED PERIOD OF TIME. • a. Overall Disincentive for Second Defined Period of Time • A disincentive deduction will be made from the payment due the Contractor if the • work assigned for the second defined period of time is not completed in 23 calendar days. For each full calendar day, or any portion of a calendar day, after the expiration of 23 calendar days that is required to complete the work, $100,000 will be deducted from the payment due the Contractor. • b. Disincentive for Ramp Closure and Construction within Second Defined Period of Time. During the second defined period of time disincentive deductions will be made from • the payment due the Contractor if the construction of the following ramps is not completed in 4 calendar days: • - the north bound entrance ramp from US 80 onto I-65; • - the north bound exit ramp from I-65 onto the Southern Bypass; • - the north bound entrance ramp from the Southern Bypass onto I-65. • The 4 calendar day time periods for the work on each ramp do not have to be the same 4 calendar day time periods. • A disincentive deduction of $10,000 will be made from the payments due the Contractor for each full calendar day, or any portion of a calendar day, after the expiration of the 4 calendar days allowed for the completion of the construction of the northbound entrance ramp from US 80 onto I-65. • A disincentive deduction of $10,000 will be made from the payments due the Contractor for each full calendar day, or any portion of a calendar day, after the expiration of the 4 calendar days allowed for the completion of the construction of the north bound exit ramp from I-65 onto the Southern Bypass. • A disincentive deduction of $10,000 will be made from the payments due the • Contractor for each full calendar day, or any portion of a calendar day, after the expiration of the 4 calendar days allowed for the completion of the construction of the north bound entrance ramp from the Southern Bypass onto I-65. • Disincentive deductions (and Incentive payments) will be calculated separately for • each ramp. • c. Overall Disincentive plus Disincentive for Ramp Closure and Construction. • Disincentive deductions will be made for the overall disincentive deduction and the • disincentive deductions for ramp closures and construction if the required work is not completed within the times allowed to avoid disincentive deductions.

  20. 5 Special Provision No. 06-0523-R2 • c. Overall Disincentive plus Disincentive for Ramp Closure and Construction. • Disincentive deductions will be made for the overall disincentive deduction and the • disincentive deductions for ramp closures and construction if the required work is not completed within the times allowed to avoid disincentive deductions. • (d) THIRD DEFINED PERIOD OF TIME. • The third defined period of time is an assignment of 30 calendar days after the completion of all of the work in the second defined period of time. This third defined time period is assigned for the continuation of the work before south bound traffic is shifted to the pavement in the median. • Incentive payments, disincentive deductions and performance bonus payments will not apply to the work done during this period of time. • (e) INCENTIVE/DISINCENTIVE FOR THE FOURTH DEFINED PERIOD OF TIME. • <skipped here for brevity> • (f) DISINCENTIVE DEDUCTIONS. • The Contractor and the State agree that the injury caused by a breach of this contract is • difficult to accurately estimate, and that the amounts of disincentive deduction are intended to ameliorate damages to the public. The Contractor agrees that the amounts of disincentive deductions are a reasonable pre-breach estimate of the probable loss to the public for the Contractor’s failure to complete the required work. • (g) LIQUIDATED DAMAGES. • Should the Contractor, or in case of default, the surety, fail to complete all of the work • required within the overall contract time, a deduction will be made for each full Calendar Day that any work remains uncompleted. This deduction shall be the amount of liquidated damages shown in the Schedule of Liquidated Damages given in Article 108.11. The deduction will be taken from any monies due the Contractor on monthly estimates. Any adjustments due to approved time extensions or overruns in the contract amount will be made on the monthly, semi-final or final estimate as may be appropriate. • Liquidated damages assessed as provided in these Specifications is not a penalty, but is • intended to compensate the State for increased time in administering the contract, supervision, inspection and engineering, particularly that engineering and inspection which requires maintaining normal field project engineering forces for a longer time on any construction operation or phase than originally contemplated when the contract period was agreed upon in the contract. Permitting the Contractor to continue and finish the work or any part of it after the time fixed for its completion, or after the date to which the time for completion may have been extended, will in no way operate as a waiver on the part of the Department of any of its rights under the contract.

  21. 1 SOUTH CAROLINA NEI EXAMPLE PROVISION SECTION 108: "NO EXCUSE INCENTIVE" COMPLETION DATE AND WAIVER OF CONTRACTOR CLAIMS. The Department will pay the Contractor a "No Excuse Incentive" if the work in the Contract is Substantially Complete prior to the "No Excuse Incentive" Completion Date of August 15.2010 subject to the conditions set forth below. Substantially Complete is defined as follows: 1.) 1-385 rehabilitation activities are complete which is defined as 1-385 North bound and South bound lanes as fully operational with the 1-385 North bound detour traffic returned to the two 1-385 north bound lanes. 2.) No pay item work remains to be finished that would require a lane closure. 3.) All safety features are installed and maintained properly. The Contractor shall provide the Engineer with written notice at least two weeks prior to reaching Substantial Completion. This is to allow the Engineer and Contractor time to jointly inspect the project and make a Substantially Complete Punch list of work to be finished. The date of Substantial Completion will be determined by the Engineer when the punch list of work is completed. The term "calendar day" as used in this Special Provision shall mean every day shown on the calendar. Calendar days will be consecutively counted regardless of weather, weekends, holidays, suspensions of Contractor's operations, delays or other events as described herein. For purposes of the calculation and the determination of entitlement to the "No Excuse Incentive“ stated above, the "No Excuse Incentive" Completion Date will not be adjusted for any reason, cause or circumstance whatsoever, regardless of fault, save and except in the instance of a catastrophic event (i.e., hurricanes or a declared state of emergency). When work is deemed Substantially Complete by the Engineer, the Contractor will be paid an incentive based on the values shown in the table below: Incentive: $25,000 for each calendar day prior to August 15, 2010 Maximum Payout Of: $750,000 The incentive will be accounted for as a lump sum addition on the Final Estimate. The Department's intent in including this incentive is to ensure substantial completion of the project(s) by the "No Excuse Incentive" Completion Date.

  22. 2 SOUTH CAROLINA NEI EXAMPLE PROVISION The parties anticipate that delays may be caused by or arise from any number of events during the course of the Contract, including, but not limited to, work performed, work deleted, change orders, supplemental agreements, delays, disruptions, differing site conditions, utility conflicts, design changes or defects, time extensions, extra work, right of way issues, permitting issues, actions of Suppliers, Subcontractors or other Contractors, actions by third parties, shop drawing approval process delays, expansion of the physical limits of the project to make it functional, weather, weekends, holidays, suspensions of Contractor's operations, or other such events, forces or factors sometimes experienced in highway construction work. SUCH DELAYS OR EVENTS AND THEIR POTENTIAL IMPACTS ON PERFORMANCE BY THE CONTRACTOR ARE SPECIFICALLY CONTEMPLATED AND ACKNOWLEDGED BY THE PARTIES IN ENTERING INTO THIS CONTRACT. AND SHALL NOT EXTEND THE "NO EXCUSE INCENTIVE" COMPLETION DATE SET FORTH ABOVE.Further, any and all costs or impacts whatsoever incurred by the Contractor in accelerating the Contractor's work to overcome or absorb such delays or events in an effort to complete the Contract by the "No Excuse Incentive“ Completion Date, regardless of whether the Contractor successfully does so or not, shall be the sole responsibility of the Contractor in every instance and no claims can be filed by the Contractor for such costs or impacts if the Contractor intends to request payment of the incentive. In the event of a catastrophic event (i.e., hurricane or a declared state of emergency) directly and substantially affecting the Contractor's operations on the Contract, the Contractor and the Department shall agree as to the number of calendar days to extend the "No Excuse Incentive” Completion Date. In the event the Contractor and Department are unable to agree to the number of calendar days to extend the "No Excuse Incentive" Completion Date, the Department shall unilaterally determine the number of calendar days to extend the "No Excuse Incentive" Completion Date reasonably necessary and due solely to such catastrophic event and the Contractor shall have no right whatsoever to contest such determination, unless the Contractor establishes that the number of calendar days determined by the Department were arbitrary or without any reasonable basis. The Contractor shall have no rights under the Contract to make any claim arising out of this "No Excuse Incentive" provision except as is expressly set forth in this Special Provision.

  23. 3 SOUTH CAROLINA NEI EXAMPLE PROVISION As conditions precedent to the Contractor's entitlement to any "No Excuse Incentive" the Contractor must: (1) Obtain Substantial Completion acceptance by the Department, as determined by the Engineer on or before the "No Excuse Incentive" Completion Date. Notify the Department in writing, within 30 days of the final acceptance of the work in the Contract by the Department, that the Contractor elects to be paid the "No Excuse Incentive" which the Contractor is eligible to be paid based on the actual final acceptance date. SUCH WRITTEN NOTICE SHALL CONSTITUTE A FULL AND COMPLETE WAIVER. RELEASE AND ACKNOWLEDGMENT OF SATISFACTION BY THE CONTRACTOR OF ANY AND ALL CLAIMS, CAUSES OF ACTION, ISSUES, DEMANDS, DISPUTES, MATTERS OR CONTROVERSIES, OF ANY NATURE OR KIND WHATSOEVER, KNOWN OR UNKNOWN, AGAINST THE DEPARTMENT, ITS EMPLOYEES, OFFICERS, AGENTS, REPRESENTATIVES, CONSULTANTS, AND THEIR RESPECTIVE EMPLOYEES, OFFICERS AND REPRESENTATIVES, THE CONTRACTOR HAS OR MAY HAVE AS TO WORK PERFORMED, WORK DELETED, CHANGE ORDERS, SUPPLEMENTAL AGREEMENTS, DELAYS, DISRUPTIONS, DIFFERING SITE CONDITIONS, UTIUTY CONFUCTS. DESIGN CHANGES OR DEFECTS, TIME EXTENSIONS. EXTRA WORK, RIGHT OF WAY ISSUES, PERMITTING ISSUES, ACTIONS OF SUPPLIERS OR SUBCONTRACTORS OR OTHER CONTRACTORS, ACTIONS BY THIRD PARTIES, SHOP DRAWING APPROVAL PROCESS DELAYS, EXPANSION OF THE PHYSICAL LIMITS OF THE PROJECT TO MAKE IT FUNCTIONAL, WEATHER, WEEKENDS, HOLIDAYS, SUSPENSIONS OF CONTRACTOR'S OPERATIONS, EXTENDED OR UNABSORBED HOME OFFICE OR JOB SITE OVERHEAD, LUMP SUM MAINTENANCE OF TRAFFIC ADJUSTMENTS, LOST PROFITS, PRIME MARK-UP ON SUBCONTRACTOR WORK, ACCELERATION COSTS, ANY AND ALL DIRECT AND INDIRECT COSTS, ANY OTHER ADVERSE IMPACTS, EVENTS, CONDITIONS, CIRCUMSTANCES OR POTENTIAL DAMAGES, ON OR PERTAINING TO, OR AS TO OR ARISING OUT OF THE CONTRACT. THIS WAIVER, RELEASE AND ACKNOWLEDGMENT OF SATISFACTION SHALL BE ALL·INCLUSIVE AND ABSOLUTE, SAVE AND EXCEPT ANY ROUTINE DEPARTMENT FINAL ESTIMATING QUANTITY ADJUSTMENTS. Should the Contractor fail to actually complete the Contract and obtain Substantial Completion by the Department as determined by the Engineer on or before the "No Excuse Incentive" Completion Date, or should the Contractor, having done so, fail to timely request the "No Excuse Incentive" for any reason, and including but not limited to the Contractor choosing not to fully waive, release and acknowledge satisfaction as set forth in (2) above, the Contractor shall have no right to any payment whatsoever under this Special Provision.

More Related