Download
standard bidding document smaller works contract sbdsc n.
Skip this Video
Loading SlideShow in 5 Seconds..
Standard Bidding Document Smaller Works Contract (SBDSC) PowerPoint Presentation
Download Presentation
Standard Bidding Document Smaller Works Contract (SBDSC)

Standard Bidding Document Smaller Works Contract (SBDSC)

100 Views Download Presentation
Download Presentation

Standard Bidding Document Smaller Works Contract (SBDSC)

- - - - - - - - - - - - - - - - - - - - - - - - - - - E N D - - - - - - - - - - - - - - - - - - - - - - - - - - -
Presentation Transcript

  1. Standard Bidding DocumentSmaller Works Contract (SBDSC) • Suitable for unit rate/lump sum • Less than us$ 10 million • Simple format • Can be adapted easily for NCB and lump sum

  2. Instructions to bidders • Works description and completion time • Eligibility and capability qualifications • Procedure for clarifications • Bid preparation - format, copies • Bid submission procedures • Language • Pricing and currencies • Price adjustment provisions (if any)

  3. Instructions to bidders (cont.) • Modification and withdrawal • Bid securities, sureties, etc. • Closing date • Opening time, date, place • Corrections • Bid evaluation criteria and procedures • Domestic preferences • Bid validity • Procedures for contract award

  4. Currency & Payment provisions • Civil works - bill of quantities • Borrower’s currency, with portions payable in foreign currency • If so, protect foreign currency component • Civil works - lump sum contracts • Sum of amounts in local currency and foreign currencies • Contract • expressed in the borrower’s currency but protect foreign currency components

  5. SBDSCConditions of contract • Organization in five chapters • General • Time control • Quality control • Cost control • Finishing the contract

  6. SBDSCConditions of contract (cont.)

  7. SBDSCConditions of contract (cont.) • Contract can be entered with foreign contractor (currencies) • Normally provides for price adjustment • Bill of quantity contract or lump sum • Sharing of risks • Provides for a project manager to supervise works and administer the contract

  8. SBDSCConditions of contract (cont.) • Some specific features of the contract conditions • Adjudicator • Reviews project manager’s decisions contested by contractor • Appointed at time of contract signing • Adjudicator’s decision final unless referred to arbitration within 28 days by either party • Time control • Acceleration/extension • Liquidated damages with ceiling

  9. SBDSCConditions of contract (cont.) • Compensation events • Not reflected in the original pricing of the contract, e.g. unforeseen ground conditions or constraints from utility companies • Entitle contractor to additional payments • Adjustment decided by project manager • If disputed, adjudicator acts • If parties agree, amount paid • If not, can be referred to arbitration

  10. SBDSCConditions of contract (cont.) • Termination for “fundamental” breach of contract • On employer’s side, essentially delayed payment • On contractor’s side, major delays and other similar defaults • Final payment rapidly settled